项目管理咨询服务合同(中英文对照)

第一篇：项目管理咨询服务合同(中英文对照)

第三条为保证乙方有效进行技术服务工作，甲方应当向乙方提供下列工作条件：甲方若已有以下资料应免费提供乙方一份；

① 建设单位情况；

② 项目建议书及批准文件；

③ 建设项目选址意见书；

④ 规划局有关规划参数的批准文件；

⑤ 经有关方面征询的地块建设项目的规划、环境保护、园林绿化、卫生防疫、水、电、煤、通信、交通和消防等； ⑥ 土地权属证明（房地产权证）及其他相关文件；

⑦ 建设基地动迁量及市政配套情况（包括动迁安置补偿情况、大市政配套情况等）；

⑧ 地形图、地质资料；

⑨ 规划设计总体位置平面图；周围环境及其规划情况；拟建项目的规划用途及分类情况；

⑩ 规划设计方案想法说明：（总建筑面积、容积率、绿化率、设计户型、结构类型、装修标准、供配电、煤气容量）⑪ 如享受减免优惠政策的文件或说明（公建配套费、人防费等）

⑫ 建设项目的资金筹措及资金流入情况；

2.其他

⑪ 甲方提供的资料应准确无误，若乙方对甲方提供的资料或数据有异议时，甲方应及时负责解答，并尽可能给乙方的工作提供方便；

⑫ 甲方应对乙方工作提供及时的、合理的相关协助。同时甲方应该提前半天通知乙方急需要解决的相关事情；

第四条甲方向乙方支付技术服务费及支付方式：

1.乙方项目管理服务费暂按万元的基数和优惠后的包干费率工程造价的1%

2.设计、勘察、监理、施工、材料招标代理费可以减免甲方部分相关费用，如甲方要收取乙方相关费用，可以在招标时招标文件中说明。

3.服务费有甲方分期支付乙方：

具体支付方式和时间如下：

a、本合同签定后3日内，甲方向乙方预付项目管理服务费的20%，作为项目启动资金；

b、施工招标代理工作完成后，甲方向乙方支付到项目管理服务费的40%；

c、根据总工期按每月平均支付项目管理服务费的95%；

d、竣工验收完毕，甲方向乙方一次性付清余款。

4.乙方开户行和帐号：

开户行：

帐号：

第五条双方确定在履行本合同期间应遵守的保密义务，乙方对甲方提供的资料按甲方的要求承担保密义务；甲方对乙方提供的成果报告等承担保密义务。

第六条本合同的变更必须由双方协商一致，并以书面形式确定。

第七条其他

1.质量奖励：

乙方将争创优质结构，甲方将按相应市优质结构单体建筑面积×5元/㎡计算给予乙方奖励。

2.文明施工奖励：

如本工程获市级文明工地，甲方将按相应建筑面积×3元/㎡计算给予乙方奖励。

3.如由于甲方的资金不能及时到位而导致的工程延误或索赔损失，由甲方承担。

4.工程筹建和施工期间有乙方原因造成工程质量问题（事故）视问题（事故）大小、责任程度，承担相关责任并予以处罚。

5.甲乙双方优势互补，乙方应充分发挥甲方的前期优势，具体合作由甲乙双方另行友好商量。

第八条双方确定在本合同有效期内，甲方指定为甲方联系人，乙方指定为乙方联系人。

第九条双方确定出现下列情况，致本合同的履行行为不必要或不可能，可能解除本合同：

1.发生不可抗力；

2.第十条双方因履行本合同而发生的争议，应当协商解决，协商或协调不成的确定按以下第2种方式处理

1.提交仲裁委员会仲裁

2.依法向工程所在地人民法院起诉。

第十一条本合同一式肆份，甲乙双方各二份，具有同等法律效力。

甲方：乙方：

法定代表人（委托）法定代表人（委托）

日期日期

3rd B, in order to ensure effective implementation of technical service, Party A to B should provide the following conditions : a buyer if it has the following information should be provided free of a B;① construction units;② project proposals and approved documents;③ construction project site submissions;④ Planning Bureau, the planning parameters of the approved documents;⑤ consult the parties concerned by the block-building projects in the planning, environmental protection, landscaping, health and epidemic prevention, water, electricity, coal, telecommunications, traffic and fire;⑥ land ownership certificates(real estate E), and other relevant documents;⑦ Construction Base Relocation Services and the amount of matching(including compensation for relocation and resettlement of large municipal matching conditions);⑧ topographic maps, geological information;⑨ position overall design plan;the surrounding environment and planning;The proposed project planning purposes and classification;⑩ Planning Design ideas :(a total construction area, the rate of volume, Green rates sized design, structure type, decoration standards for distribution, and Gas capacity)⑪ relief enjoy preferential policies such as a document or(build public support charges air defense fees)⑫ construction project financing and capital inflows;2.⑪ other information provided by the buyer should be accurate, if Party A Party B of the information or data object, Party A shall be responsible for the timely answer, as far as possible, to the B side and facilitate the work;⑫ Party A Party B should provide timely, reasonably related assistance.Meanwhile buyer should advance the half-day notice B is an urgent need to resolve the relevant issues;4th of Party A to B to pay service fees and payment methods : 1.B project management service charges apply the million base and preferential rates responsibility for the cost of 1% 2.design, inspection, supervision and construction, materials bidding fee waiver buyer can be part of the related costs, such as Party A Party B charge related costs, in the tender, the tender document stated.3.Party A service fee is paid by phases B : specific mode of payment and time are as follows : a.The contract signed after three days Party A to B advanced project management services fee of 20%, as the project start-up capital;b, Construction bidding completed, the buyer paid to B of the project management services of 40%;c, According to the total period by the average monthly pay of project management services fees 95%;d, acceptance tests completed, Party A to B lump-sum balance.4.B depositary Bank and Account : Bank accounts : account : fifth of the two sides established in the performance of this contract period shall comply with the obligation of confidentiality Party A Party B of the information provided by the buyer asked to assume the obligation of confidentiality;Party A Party B of the report on the outcome assume obligation of confidentiality.Sixth of the contract changes must be made by both sides consensus in written form and identify.Seventh of the other one.Quality Incentives : B to achieve high-quality structure, Party A will be of high quality structure corresponding monomers City area × 5 yuan / ㎡ calculating B award.2.Civilized Construction Award : If the project site is a civilized city, Party A will be a corresponding area × 3 yuan / ㎡ calculating B award.3.Party A as a result of the funds were not in place in time which led to the delay or loss claimed by the buyer commitment.4.Project planning and construction period B causes the quality of the project(1998)as the(1998)size, level of responsibility to shoulder responsibility and be punished.5.Consists of two complementary strengths, B should give full play to the buyer early advantage consists of concrete cooperation by the two sides further friendly discussion.The two sides established the 8th of this contract period, the buyer designated as the buyer contacts, B to B designated contacts.Article 9 of the parties identified in any of the following situations, to the fulfillment of this contract acts unnecessary or impossible, possible lifting of the contract : 1.force majeure;2.Both sides of the 10th because of the discharge of the

contract and the dispute should be resolved through consultation.consultation or coordination failures identified by the following paragraph two ways to deal with one.submitted to arbitration 2.according to the works to a people's court.Article 11 of this contract were a carry, both the first and second sets, has the same legal effect.Party A : B : legal representative(commission)legal representative(commission)

第二篇：中英文项目合同对照

PROJECT CONSULTANCY CONTRACT 项目顾问合同

For（）project

Between

XXXXXX

represented by Mr.hereinafter referred to as “”-

甲方：有限公司

代表人：

（以下简称甲方）

and

XXXXXXX

Mr.Amsterdam

The Netherlands

represented by Mr.hereinafter referred to as “” –

乙方：

代表人：

（以下简称乙方）

1.Terms of the contract 合同条款

XXXXX authorizes XXXXX to implement the consultancy to the preliminary design concept of XXXXX project, and to assist XXXXX in completing preliminary design drawings.甲方授权委托乙方执行其在XXXXX展示工程初步设计概念的顾问工作，并帮助甲方完成初步设计稿。

2.Project stages项目阶段

The project shall be carried out in cooperation and in close guidance by the XXXXXX.The general consulting plan shall be provided before the design starts, a detailed plan shall be sent to XXXXX after each biding conference or press release meeting as follows: An idea explanation presentation shall be showed within 7 days after the tender starting date.A draft design drawing shall be submitted within 7 days after the first presentation meeting between XXXXXXXX and XXXXXXXX.Following the meeting of draft design drawing, a number of amendments requested by X shall be carried out.The final presentation of the preliminary design shall be submitted within 3 days before the bidding deadline to assist XXXXX in completing the tendering documents.本项目应在相互合作以及吸取XXXXX指导方针的前提下开展。乙方应在设计前期提供整体咨询计划书，每次招标或信息发布大会后，乙方也应按如下提供详细计划：投标开始后的七日内向甲方展示初步设想；设想探讨会议结束后的七日内递交设计草图，递交后，乙方须执行甲方的修改要求；最终初始设计稿应在招标截止期前三天内交予甲方，从而帮助甲方整理其投标文件。

3.Term of validity合同效力期限

The consultancy contract shall apply from 1 Jan 2011 to 31 December 2012.此项目顾问合同适用于2011年1月1日至2012年12月31日。

4.Force Majeure不可抗力

“Force Majeure” under the contract means the external circumstances that can not be foreseen, avoided and surmounted in the process of fulfilment of the contract, the incidents of which makes either party fails to fulfill the obligations under the contract, such as wars, riots, government behaviors, earthquake, fire, storms, floods or other severe weathers.本合同下的“不可抗力”是指在执行合同的过程中不能被预见、避免、克服的外在因素，从而导致合同任意一方无法履行合同责任，如战争、**、政府行为、地震、火灾、风暴、洪水或其他恶劣天气。

The period required to complete the obligations shall be extended accordingly due to the affect of the force majeure, the extension shall be the same as the period of time affected by the force majeure or the period of time is agreed upon both parties.由于不可抗力造成的影响，履约责任期可被相应延长，延长期应与不可抗力的影响期相同或通过双方协商确定。

5.Intellectual Property Rights and confidentiality 知识产权与保密

XXXXX shall ensure that the results of his design are not with any flaw to any right and none of the rights of third parties is impinged, and shall ensure that XXXXX is not

claimed by any third party for using XXXXX's design results to be against the intellectual property rights.Should the case above occur, XXXXX shall be responsible for disposing and assuming all legal liabilities arised therefrom.乙方应确定其设计不存在任何所有权瑕疵，不会牵涉到任何第三方的权利，并保证甲方不会因使用乙方的设计而产生侵权赔偿。如果发生上述情况，乙方应负责处理所有因此造成的法律责任。

All texts, graphics, charts, datas and other documents described about this project are the properties belonging to XXXXX.XXXXX shall not disclose any information of this project to any third party without authorization, shall not use any of the documents and informations above in any other project, otherwise, all resulting legal liabilities shall be assumed by XXXXX.本项目涉及的所有材料均属于甲方。乙方在未授权的情况下，不应向任何第三方透露本项目的任何信息，也不能在其他项目中使用本项目的任何资料与信息，否则，由此产生的法律责任由乙方负责。

The copyright(except authorship)of the design results in this project is belonging to XXXXX.XXXXX shall not use the design results under this project on the irrelated

intentions and purposes to the project, shall not authorize any third party or disclose any content of the design results.XXXXX may inform XXXXX before using the design results submitted by XXXXX on other occasions besides this project, XXXXX shall not have any right to reject the foregoing acts.本项目涉及的所有版权（除著作权外）均属于甲方，乙方不得在与本项目无关的意图或目的下使用其设计成果，也不可以授权第三方或透露任何设计细节。甲方在与本项目无关的场合下使用乙方提交的设计成果，可提前告知乙方，乙方无权拒绝前述行为。

All technologies, laws and financial informations relating to this contract are trade secrets, shall not be disclosed to the third parties listed out of the contract without the consent of all parties under the contract, otherwise, the telltale party shall be liable to assume 10% of the total contract price for breach of the contract to the other party.Should the compensation not be sufficient for the actual losses, the amount of the compensation shall be increased in accordance with the actual losses.与本项目相关的所有技术、法律和金融信息都被视为商业秘密，任何一方不得透露给合同外的第三方，否则，泄密的一方因违约须赔偿合同总额的10%予另一方。如果赔偿不足以赔付实际损失的，赔偿额应根据实际损失相应的增加。

The terms of intellectual property and the duty of confidentiality shall not be invalidated by the completion of the execution, change, termination and inefficacy of the contract.知识产权和保密责任条款不应随工作的完成或合同的变更、终止和失效而无效。

6.Payment款项

Payments shall be made as follows:

The budget of RMB 430,000 is payable in three installments.The first installment shall be 30% of the budget(RMB 129,000), the second installment shall be 30% of the budget(RMB 129,000), the third installment shall be 40% of the budget(RMB 172,000).Payments shall be made to the account of XXXXX Design B.V..款项支付情况如下：

合同款共43万人民币，分三期支付，第一期、第二期各支付总款项的30%（即壹拾贰万玖千元整），第三期支付总款项的40%（即壹拾柒万贰千圆整）。款项应汇入XXXXX的银行账户：

7.Scope of service服务范围

XXXXX shall provide the individual services described during the specified time period.The decision as to the priority of the individual measures shall be taken by mutual consent together with XXXXX.The individual services are as follows:

乙方应在各时间段内提供相应的服务。各类方案的优先权应在甲乙双方一致同意的情况下决定。服务内容如下：

Design Concept

XXXXX assists XXXXX to complete the design concept for Shanghai Nature History Museum(subbranch of Shanghai Science and Technology Museum)project based on a high international standard.设计概念

乙方协助甲方确定上海自然博物馆（上海科技馆分馆）项目的设计概念，并保证概念的国际化高标准。

Consultancy

XXXXX offers individual consultanting services to XXXXX in different phases of the project and direct XXXXX to a way of which a proper design result could come out.Experienced and qualified experts shall be transferred to XXXXX during the design period as required.咨询顾问工作

乙方向甲方提供不同阶段的咨询顾问服务，引导甲方更好的完成设计成果。设计期内，乙方应根据需要将有经验和资质的专家调职到甲方。

Presentations

XXXXX is in charge of all the presentations designed for Shanghai Nature History Museum(subbranch of Shanghai Science and Technology Museum).XXXXX shall ensure the quality of the presentation with XXXXX’s advices.方案介绍

乙方负责所有需为XXXXXX设计的方案展示。在甲方的意愿下保证方案展示的质量。

Design drawings

XXXXX shall assist XXXXX in design drawing details if necessary.设计图

在甲方需要的情况下，乙方应在设计图细节方面给予协助。

8.Provision of third party services 第三方服务条款

Where services are provided by third parties(e.g.printing, etc.), XXXXX shall monitor production and guarantee that the service is performed competently.Payment for this service is covered by the overall budget.由第三方提供服务的地方，乙方应监督制作及保证服务质量。此服务涉及的费用包含在总预算中。

9.Liability and acceptance 责任与验收

Approval/acceptance 批准/验收

authorised contact person who may approve content for design or authorise a representative to carry out this duty.甲方指派XXXXX先生作为联系代表，电子信箱为XXXXX@dg.com，联系代表有权批准服务内容或授权另一代表执行此职责。

10.Concluding provisions 最后条款

Amsterdam shall be the place of performance.Should individual provisions of this contract be invalid, this shall not affect the validity of the other provisions.An effective provision which most closely reflects the commercial purpose of the parties must be agreed upon in place of the invalid provisions.This Agreement is made in both Chinese and English;in the event of any divergence between the two versions, Chinese version shall prevail.阿姆斯特丹为所有工作执行的地点。如果本合同中个别条款无效，无效条款不应影响其它条款的效力。最能反映当事人商业目的的有效条款必须得到双方的商定以代替无效条款。本协议以中英文书就，若两种版本之间出现分歧，则以中文版为准

Approved by

有限公司XXXXX

XXXXX

____________________________________________________

第三篇：中英文合同对照（范文模版）

房地产买卖协议

SALES CONTRACT FOR REAL ESTATE

出售方：

（以下简称“甲方”）

买受方：

（以下简称“乙方”）

中介方：上海臣信房地产经纪有限公司（以下简称“丙方”）

Seller:

（hereinafter “Party A”）

Buyer:

(hereinafter “Party B”)Broker：Shanghai Chenxin Real Estate Co., Ltd.（hereinafter “Party C”）

经丙方中介介绍，甲、乙双方就上海市__________区__________路______弄__________号______室及__________车位（以下简称“该房地产”）的转让事宜，签订本协议，协议内容如下（有□选择的，以√为准）：

With the introduction of Party C, Party A and Party B enter into the agreement concerning the transfer of ____ Suite and its ancillary carport located at ____ of _____ Alley, _____Avenue _____District of Shanghai(hereinafter as “Real Estate”)detailed as follows(“√” shall be filled in the corresponding“□”, if appropriate):

一、【该房地产基本情况】

1.BASIC INFORMATION

1、该房地产：房地产权证书号为：______________；房屋面积：____________平方米；车位面积：___________平方米。

2、该房地产 □ 已 □ 未设定抵押。

3、该房地产 □ 已 □ 未出租。若该房地产已出租，则甲方应保证承租人已经放弃优先购买权，若因承租人以优先购买权引发纠纷，则甲方愿意承担全部法律责任。

4、有关该房地产的权属情况，若上述填写资料与实际情况不符或不详尽的，以上海市房地产登记簿记载的信息为准。

1)Certificate of title to this real estate is numbered as __________ with floor space of ______ ㎡and the related carport are ______ ㎡.2)Mortgage is made on this real estate: □ Yes

□ No.3)This real estate has been leased: □ Yes

□ No.If “Yes”, Party A shall guarantee that lessee has waived the right of preemption.Any and all legal liabilities arising out of or in connection with the exercise of such rights by lessee shall be borne by Party A.4)If the title of this real estate mentioned above is not clearly indicated or is incorrect, information listed in the register of Shanghai Real Estate Office shall be applied.二、【转让总价及定金与款项的选择适用】

2.TRANSFER PRICE AND DEPOSIT, OPTION OF PAYMENT

甲乙双方明确，该房地产的转让总价款：人民币大写_______________元（其中含车位转让款人民币___________元）。乙方于签署本协议时，支付诚意金人民币__________________ 元至中介方，并委托中介方与甲方洽谈；若甲方接受交易条件并签署本协议，则乙方委托中介方将诚意金转交给甲方作为款项。若至_ ___年_____月____日，甲方仍未签署本协议的，则乙方有权至中介方处无息取回诚意金；若乙方未按时取回诚意金，则视为继续委托中介方与甲方洽谈。本协议签订当日乙方直接向甲方支付款项人民币_____________________元。甲方同意在本合同签订后

日内，乙方向甲方支付款项人民币

元，该款项由乙方或乙方授权的其他人以现金方式交付或支付至甲方的指定账户，若采用支付至甲方指定账户的，下述账户已为甲方所确认：

户名：_________________ 账号：___________________ 开户行：________________

Party A and Party B expressly agree that the total transfer price of this real estate is CNY ________ inclusive of transfer price of carport as CNY _______.Party B agree that it shall pay Earnest Money as CNY ________ to Party C at this contract date and entrust Party C to negotiate with Party A.if Party A accept and sign this contract, Party B may authorize Party C to transfer such Earnest Money to Party A as deposit;provided, however, Party B may require the repayment of Earnest Money free of interests by Party C if Party A fail to sign this contract prior to ___________.In such event, it shall constitute that continue entrustment has been granted to Party C if Party B fail to take such Earnest Money in due time.Party B shall pay CNY __________ to Party A directly as deposit at this contract date.Party A agree that Party B may pay CNY __________ to it as deposit within ______ days from this contract date.Such deposit shall be paid in cash by Party B or its designee or made through T/T to the following bank account affirmed by Party A: Account Holder: ________Bank Account: _______ Bank Name: _________

三、【买卖交易细则】

3.SALES RULES

1)转让总价款：人民币大写_______________ _________元（其中含车位转让款人民币大写______________________ 元）。

2)双方同意按以下方式支付款项：

第一笔房款： 甲、乙双方同意自《上海市房地产买卖合同》示范文本签订后_____日内，乙方向甲方支付的上述款项 人民币_________元作为乙方支付的首笔房款。第二笔房款：乙方于______年_____月_____日前，支付甲方房款人民币___________________元。

第三笔房款：可按以下情况选择支付方式：

□ 乙方通过银行按揭贷款的方式向甲方支付第三笔房款人民币__________________元，该款项由

银行在取得抵押人为乙方的他项权利证明后直接划入甲方帐户。□ 甲乙双方同意共同至房地产交易中心办理该房地产过户手续，并取得房地产登记处的核发的收件收据后_____日内，乙方向甲方支付房款人民币________________元。

第四笔房款：□在办妥房屋交付手续当日，乙方向甲方支付房款人民币___________________元。

□甲乙双方同意，在签署买卖合同时将交房款人民币____________元交丙方监管至房屋交付手续办妥之日，丙方凭《房屋交接书》向甲方支付上述款项。

1）The total transfer price of this real estate is CNY ________ inclusive of transfer price of carport as CNY _______.2）Such transfer price shall be made in installments as follows:

The first installment shall be made to Party A by Party B as CNY ________(inclusive of deposit)within ______ days from commencement date of Sales Contract for the Real Estate Located in Shanghai City(“Sales Contract”).The second installment as CNY ______________shall be made to Party A by Party B prior to ___________.The third installment may be made as follows:

□ CNY _________ as third installment shall be made to Party A by Party B through bank mortgage loans, which shall be directly paid to Party A’s bank account upon the certificate evidencing Party B as mortgagor has been presented to the lending bank, provided, □ Party A and Party B agree to fulfill the transfer formalities for this real estate before Real Estate Trading Center and Party B shall pay Party B CNY _____________ within _____days upon the certificate issued by real estate register has been received.The fourth installment as CNY _____________ shall be paid.□ To Party A by Party B at the date on which the transfer formalities of this real estate has been fulfilled;or □ to Party A by Party C upon the receipt of Deed of Transfer if, as agreed by Party A and Party B, CNY _______ equal to such fourth installment has been delivered to Party C for escrow until the full fulfillment of transfer formalities.3）产权过户：待该房地产之抵押登记（若有）已经注销且乙方申请的按揭贷款（若有）经银行审核通过，具备过户条件具备后，最晚不迟于______年_____月_____日，共同至该房地产所在区交易中心办理房地产过户手续。3）Transfer.Within _____ days upon the revocation of mortgage registration for this real estate(if any)and the loans acquired by Party B therefore(if any)satisfying the applicable requirements after the review of related bank(in no event late than _______), Party A and Party B shall fulfill the transfer formalities before the trading center of that district where this real estate is located.4）房屋交付：甲方于收到乙方全部转让款项当日，将该房地产交付乙方，双方应签署《房屋交接书》。交付前的物业管理费及公用事业费由甲方承担，交付后的物业管理费及公用事业费由乙方承担。固定装修、附属设施设备以及经甲乙双方确认的家电、家具等价格已经包含在该房地产转让总价款内，甲方须保证该房屋内附属设施、设备均能正常使用及室内装饰与签订买卖合同之日的状况相符。

4）Delivery.At the date on which all transfer prices，party A shall deliver this real estate to Party B and the Certificate of Transfer and Handover shall be concluded by the Parties therefore.Property Management Fees and Utilities Expenses arising out of or in connection with this real estate shall be borne by Party A prior to such delivery, or shall be borne by Party B upon such delivery.Charges or expenses related to the fixtures and ancillary equipments & facilities of this real estate, as well as the prices of home appliances and furniture agreed by the Parties, have been included in the transfer price and Party A guarantee that all such ancillary equipments & facilities may work properly, all interior decorations thereof satisfy the conditions provided herein.5）相关费用：Miscellaneous Charge.[交易税费]：双方同意，交易中所涉及的上述买卖双方的税费由 □各自承担并支付；□由甲方承担并支付；□由乙方承担并支付。

[公证费]：若交易涉及买卖合同公证，费用由□双方分担并支付；□由甲方承担并支付；□由乙方承担并支付。

[中介报酬]：对于中介方提供中介服务所产生的报酬事宜，详见附件“中介服务确认书”。

Trade Tax.The Parties agree that any and all taxes and charges arising out of transaction hereunder shall be borne and paid by □ Party A;or □ Party B.Notary Fees.Any notary fees arising out of or in connection with transaction hereunder shall be borne and paid by □ Party A;□ Party B;or □ Party A and Party B.Brokerage fees.Brokerage feess paid to broker for any brokerage service provided shall be detailed in attached Schedule “Acknowledgement of Brokerage fees”.四、【法律责任的选择适用】

4.APPLICATION OF LEGAL LIABILITIES

甲方保证该房地产产权清晰、权属明确，无异议登记、单方预告登记，无司法、行政查封等限制性交易情形存在；若因本条所述情况导致本协议效力瑕疵，甲方应返还乙方所有已付房款并赔偿乙方实际损失。

Party a guarantees that it has full and clear ownership to this real estate, which is free of any dispute registered, unilateral advanced registration, judicial or administrative attachment or other events restricting trades.If any defect affecting the validity of this Contract is occurred due to any misrepresentation hereunder, Party A shall refund all transfer prices paid by Party B, and indemnify any and all losses and damages suffered by Party B there-from.五、【争议解决】

6.DISPUTE SETTLEMENT

各方在本协议履行过程中发生争议的，应友好协商；协商不成的，应向该房地产所在地人民法院起诉。

Any dispute arising out of or in connection with the performance hereof shall be settled by amiable negotiation, if fails, either Party may bring a lawsuit before the People’s Court with jurisdiction where this real estate is located.六、【合同效力】

6.VALIDITY

本协议自甲、乙双方签署起对甲、乙生效，丙方签署后对丙方生效，一式三份，甲、乙、丙三方各执一份。

This Contract shall have binding force to Party A and Party B upon signatures of such two Parties are made hereon, and shall have binding force to Party C if signature of Party C is also made hereon.This Contract shall be executed in triplicate and each Party shall have one copy.

第四篇：各类合同中英文对照描述

退运换货协议Agreement on Returning and replacing Goods

compensation agreement索赔协议

劳动人事方面包括：劳动合同（labor contract）、保密协议

（confidentiality agreement）、竞业禁止协议（non-compete

agreement）、人事代理协议（human agency agreement）；

不动产方面包括：商品房买卖合同（contact of sale of commodity

houses）、租赁协议（tenancy agreement）、土地使用权出让、出租、转让合同（contract for assignment，lease and transfer of

the right to the use of land）、抵押合同（mortgage contract）、贷款合同（loan contract）、物业管理合同（property management

contract）、建设工程承包、安装合同（contract for construction

engineering and installation of project）；

服务类包括：技术服务（technical service agreement）、咨询

(technical consultant agreement)、开发（technical development

agreement）、转让（technical transfer agreement）、许可协议

（licensing agreement）、代理协议（agency agreement）、保

险合同（insurance contract）、融资协议（financing agreement）、风险投资管理协议（venture capital management agreement）、法律顾问协议（employment contract for legal consultant）；

公司方面包括：合资企业（joint venture contract）、章程（articles

of association, corporate bylaw）、合伙协议（partnership

agreement）、股权转让协议（agreement on assignment of equity

interests）、和解协议（composition agreement）；

物流方面包括：

买卖合同（sales contact）、采购合同（purchase contact）、运输合同（carriage contact）、进出口合同（import and export

contact）、仓储保管合同（warehousing and safe-keeping

contact）、补偿贸易合同（contact for compensation）

人身方面包括：遗赠抚养协议（legacy-support agreement）、离婚协议（divorce agreement）

无偿合同nude contract contract without compensation;gratuitous contract;naked contract

第五篇：项目咨询服务合同

项目申报咨询服务合同

委托方（甲方）：项目联系人：电话：

受托方（乙方）：杭州市千里目营销策划有限公司

项目联系人：电话：

本合同就申报_____________________________________________________项目进行申报咨询服务，并支付咨询报酬。双方经过平等协商，在真实、充分地表达各自意愿的基础上，根据《中华人民共和国合同法》的规定，达成如下协议，并由双方共同恪守。

第一条 乙方进行项目咨询的内容、要求和方式：

1．咨询内容：在甲方提供准确、完善的可行性研究基础数据的前提下，乙方代写上述项目的申报材料。

2． 咨询方式： 乙方按照项目规定的时间和进度及时申报上述申报项目。

第二条 为保证乙方有效进行技术咨询工作，甲方委托专人与乙方密切保持

联系。

第三条 甲方向乙方支付咨询报酬及支付方式为。

咨询报酬总额为：

1、甲方支付乙方申报材料咨询服务费政府无偿资助资金总额(包含地方基金、地方配套资金)或者贷款贴息部分的15%支付乙方作为酬劳，甲方必须从自有资金中列支该笔费用。

2、咨询服务费研报告、执行全部网上申报流程、纸质文件递交的工作，不包括其它服务内容。具体支付方式和时间如下：

本合同签订之日起三日内，甲方支付乙方前期申报材料咨询服务费总额的100%。项目申报成功后，甲方收到第一笔资金后五个工作日内一次性全额支付

乙方无偿资助资金总额或贷款贴息部分总额的15%。如延期支付，需支付乙方0.3%/日的滞纳金。

乙方开户银行名称、地址和帐号为：

开户银行：开 户 名：帐号：

第四条 双方确定，在本合同有效期内，甲方指定为甲方项目联系人，乙方指定为乙方项目联系人。

一方变更项目联系人的，应当及时以书面形式通知另一方。未及时通知并影响本合同履行或造成损失的，应承担相应的责任。

第五条 如果因为乙方对政策判断错误或者编制材料出现严重错误造成项目申报失败，乙方退还甲方元申报材料咨询服务费。

第六条 双方确定，出现发生不可抗力等情形，致使本合同的履行成为不必要或不可能的，可以解除本合同。

第七条 双方因履行本合同而发生的争议，应协商、调解解决。协商、调解不成的，可提交有管辖权的人民法院诉讼解决。

本合同有效期自合同签订之日起生效，双方完整完成合同内容即失效。

第九条 本合同一式

第十条 本合同经双方签字盖章后生效。

甲方 ：（盖章）法定代表人／委托代理人：年月日

乙方： 杭州市千里目营销策划有限公司（盖章）

法定代表人／委托代理人：

年月日